Chase Precast Corp. v. John J. Paonessa Co.

490 Mass. 371, 566 N.E.2d 603 (1991)

Quick Summary

Chase Precast Corp. (plaintiff) and John J. Paonessa Co., Inc. (defendant) were involved in a dispute over a contract for concrete median barriers for a Massachusetts highway project. When residents sued to stop the barrier installation, leading to a change in project requirements, Chase sought to recover lost profits for barriers not produced.

The main issue was whether frustration of purpose could be used as a defense by Paonessa to avoid paying damages. The Supreme Judicial Court of Massachusetts affirmed that Paonessa was excused from its obligations because neither party could have foreseen the significant alteration in project requirements.

Facts of the Case

Chase Precast Corporation (plaintiff) had a contract with John J. Paonessa Company, Inc. (defendant), to supply concrete median barriers for a highway project undertaken by the Massachusetts government. The project involved resurfacing highways and replacing grass medians with concrete.

Residents opposed the removal of the grass median strips, leading to a lawsuit that halted the project. As a result, the Commonwealth of Massachusetts amended their contract with Paonessa, removing the requirement for the median barriers.

Chase had already produced and delivered about half of the barriers when Paonessa, anticipating changes due to the litigation, asked Chase to stop production.

Although Chase was paid for the barriers produced, they sought to recover lost profits for the unproduced portion of their contract with Paonessa. Paonessa, in turn, sought indemnification from the Commonwealth should they be found liable to Chase.

Procedural Posture and History

  1. The Superior Court ruled in favor of Paonessa based on the doctrine of impossibility of performance.
  2. Chase and Paonessa cross-appealed the decision to the Appeals Court.
  3. The Appeals Court affirmed but indicated frustration of purpose as the more accurate basis for the decision.
  4. Chase then appealed to the Supreme Judicial Court of Massachusetts.

I.R.A.C. Format


Whether the doctrine of frustration of purpose is a valid defense in a breach of contract action in Massachusetts and whether it excuses Paonessa from fulfilling its contract with Chase.

Rule of Law

The doctrine of frustration of purpose may be invoked when an unforeseen event, not caused by either party and not allocated by the contract, destroys the value of performance, thus excusing the parties from further obligations.

Reasoning and Analysis

The court recognized that both doctrines of impossibility and frustration concern the impact of unforeseen circumstances on contractual obligations. In this case, while performance by Paonessa was still possible, the purpose of the contract was frustrated by the litigation and subsequent change in government policy.

The court concluded that neither party could have anticipated such a significant alteration to a standard practice within highway projects, such as installing median barriers. The court also noted that Chase was aware of the Commonwealth’s standard contracts, which included provisions for altering project requirements.

Therefore, Chase should have understood that there could be changes to their supply agreement with Paonessa. Consequently, Paonessa’s defense of frustration of purpose was upheld because the risk of cancellation was not expressly assumed in their contract with Chase.


The Supreme Judicial Court of Massachusetts affirmed the lower court’s decision that Paonessa was excused from its contractual obligations based on the doctrine of frustration of purpose.

Key Takeaways

  1. Frustration of purpose can be a valid defense in Massachusetts breach of contract actions when events beyond either party’s control negate the value of contract performance.
  2. Paonessa was not liable for Chase’s lost profits because the risk of project changes was not specifically assigned to Paonessa in their contract.
  3. The court’s decision takes into account industry standards and prior knowledge of potential changes to contractual obligations due to government action.

Relevant FAQs of this case

What differentiates frustration of purpose from impossibility of performance in contract law?

Frustration of purpose occurs when an unforeseen event fundamentally changes the reason for a contract, while impossibility of performance happens when an event renders the contract impossible to fulfill.

  • For example: If a concert is cancelled due to the unexpected illness of the star performer, ticket vendors may invoke frustration of purpose to refund customers, as the primary purpose—seeing the star perform—is no longer possible, despite the practical ability to still hold an event.

How does foreseeability affect the application of frustration of purpose doctrine?

If a contracting party could have foreseen an event that might alter the contract’s purpose, the frustration of purpose defense is less likely to be successful.

  • For example: If a wedding venue is booked during hurricane season, and a storm disrupts the event, the doctrine may not apply because such risks are foreseeable during that time of year.

Is it always necessary to have a change clause in contracts to handle unforeseen circumstances?

While not mandatory, including a change clause is prudent to provide guidance on how unforeseen circumstances will be managed and to avoid litigating unallocated risks when events change contractual duties.

  • For example: A construction contract might include a force majeure clause allowing for extension of time or modification of terms if natural disasters occur, thus providing a clear framework for both parties.


Last updated

Was this case brief helpful?

More Case Briefs in Contracts